Morrison Foerster’s Government Contracts Insights provides our in-depth analysis of developments and trends impacting government contracting. Through Insights, our attorneys offer a real-time assessment of the statutory, regulatory, legal, and business-related developments and trends that are shaping the industry. We also examine a full array of non-U.S. public procurement issues, mindful that our clients compete in a global marketplace.Morrison Foerster’s nationally recognized Government Contracts and Public Procurement practice represents the world’s leading companies in the aerospace and defense, intelligence, cybersecurity, information technology, financial and professional services, education, healthcare, infrastructure, and logistics support sectors. We are enlisted to address our clients’ most complex and important legal issues. Our work includes contract and subcontract negotiation and other transactional matters, business and regulatory compliance counseling, internal investigations, bid protests, and a wide array of enforcement and litigation matters. Our clients range from Fortune 50 companies to small and medium-sized companies just entering the public sector. We advise both U.S. and non-U.S. companies involved in municipal, state, federal, and non-U.S. procurement matters.<h2>ABOUT MORRISON FOERSTER</h2>Morrison Foerster is a leading global law firm that transforms complexity into advantage for its clients. Our clients include some of the largest financial institutions, banks, consulting and accounting firms, and Fortune 100, technology, and life sciences companies. Highlighting the firm’s commitment to client service, leadership in market-changing deals and impact litigation, and values-based culture, Morrison Foerster has been repeatedly recognized as one of the top 10 firms on The American Lawyer’s A-List. Year after year, the firm receives significant recognition from Chambers and The Legal 500 across their various guides, including Global, USA, Asia‑Pacific, Europe, UK, Latin America, and FinTech Legal. Our lawyers passionately care about delivering legal excellence while living our values. Morrison Foerster has a long-standing commitment to creating a culture that respects and celebrates differences, while providing an inclusive environment. The firm has achieved Mansfield Certification Plus since 2018 as a result of successfully reaching at least 30 percent women, communities of color, and LGBTQ+ lawyer representation in a notable number of current leadership roles and committees. The firm also has a long history of commitment to the community and society through providing pro bono legal services, including litigating for civil rights and civil liberties, improving public education and fostering the wellbeing of children, advocating for veterans, promoting international human rights, enforcing the right to asylum, and safeguarding the environment.

Social

Search

GAO Protest Timeline

govcon-gao-protest-timeline-thumb.jpg

Govcon GAO Post Award Protest Timeline Article

Contract Disputes Act Claim Timeline

govcon-contract-disputes-timeline-thumb.jpg

The Bayh-Dole Act

govcon-bayhdole-thumb.jpg

Anatomy of a Protest

govcon-federalclaimsprotest-thumb.jpg

Allowability of Legal Costs

govcon-allowabilityoflegalcosts-thumb.jpg

Procurement Integrity Act

240715-procurement-integrity-act-resized.jpg

Govcon-Resources

Tina is Co-chair of Morrison Foerster’s Government Contracts & Public Procurement practice. She represents a wide variety of government contractors including information technology, defense, biotechnology, and pharmaceutical companies, with a focus on general contract counseling and compliance, particularly concerning intellectual property, and cybersecurity matters and federal grant funding.Tina counsels contractors on compliance with federal, state and local acquisition and ethics regulations and with the evolving myriad of requirements pertaining to data security and cybersecurity. She has been involved with numerous internal investigations and compliance reviews, and with mandatory and voluntary disclosures to agencies, and litigation of False Claims Act matters.Tina routinely advises clients concerning:<ul><li>Prime-subcontractor relationships</li><li>Sources of supply and country of origin requirements</li><li>Price reductions and price reporting issues</li><li>Organizational conflicts of interest</li><li>Safeguarding of intellectual property and other proprietary interests</li><li>Licensing and data rights issues</li><li>Handling of classified materials and controlled unclassified information</li><li>Agency suspension and debarment proceedings</li></ul>She also assists clients with due diligence and other activities related to the acquisition of government contracting concerns, and with the drafting and negotiation of teaming agreements, subcontracts, licensing agreements, and cooperative research and development agreements. She also assists clients applying for federal grants (including SBIR and STTR agreements), and those who seek to obtain other transactional authority agreements, as well as those competing for state and local government work.Tina’s litigation experience includes government contracts claims litigation in federal courts and before boards of contract appeals, bid protests before the Government Accountability Office and the Court of Federal Claims, and complex disputes in federal courts, including civil fraud and False Claims Act litigation and reverse Freedom of Information Act litigation.Prior to joining Morrison Foerster, Tina worked at another large national firm and as a trial attorney in the Office of the General Counsel of the Navy, Navy Litigation Office.<h4>Representative Experience</h4><ul><li>Negotiation of largest CHIPS Act federal funding agreement between multinational semiconductor corporation and U.S. Department of Commerce.</li><li>Negotiated prime contract and major subcontracts related to the Department of Energy’s next generation supercomputer program, including extensive IP rights negotiations and negotiation of associated patent rights waivers.</li><li>Negotiated series of other transaction authority agreements with DARPA and associated subcontracts with more than a dozen research universities on behalf of a firm biotech client, including complex IP rights allocations and material transfer agreements.</li><li>Assist clients with FedRAMP authorization process and with development of license agreements for software products sold to federal, state and local government agencies.</li><li>Cyber incident response counseling to some of the largest companies and organizations impacted by security incidents.</li><li>Advises clients on Bayh-Dole reporting of inventions and IP strategies for contracts and grants.</li><li>Conducts due diligence for major government contract mergers and acquisitions.</li></ul>

reynolds_tina_blog_150x150.png

reynolds_tina_common_640x280.jpg

reynolds_tina_heroretina_2700x1160.jpg

reynolds_tina_mobileretina_750x1040.jpg

reynolds_tina_social_600x600.jpg

Partner

Tina is co-chair of Morrison Foerster’s Government Contracts & Public Procurement practice. She counsels a wide variety of government contractors on compliance with federal acquisition and ethics regulations. She drafts and negotiates contracts on their behalf and has been involved with numerous internal investigations and compliance reviews, and with bid protest, contract claims, and False Claims Act litigation. She also advises on M&A transactions involving government contractors.

Tina D. Reynolds

Jim Tucker is of counsel in Morrison Foerster’s Government Contracts and Public Procurement Practice Group and is based in the firm’s Washington, D.C. office.Jim’s practice runs the gamut of litigation and counseling in federal procurement matters, with an emphasis on bid protests, Cost Accounting Standards disputes, and small business matters. He has represented both protesters and awardees in scores of protests before the Government Accountability Office, the Court of Federal Claims, and procuring agencies, in acquisitions ranging from small business procurements to multibillion-dollar contracts of global significance. His representative protest matters span the aerospace sector, the Intelligence Community, base operations and logistics, healthcare, nuclear and environmental work, and information technology and software acquisitions. His protests have included both classified and unclassified programs. In addition to prevailing in published decisions, Jim has also secured favorable corrective action on behalf of clients in a wide variety of protests that were resolved without a published decision.Jim’s work also focuses on disputes over cost allowability and compliance with the Cost Accounting Standards, and he has appeared before the Armed Services and Civilian Boards of Contract Appeals, in size and status protests before Small Business Administration (SBA) area offices, and appeals before the SBA Office of Hearings and Appeals. Jim regularly counsels clients on contract interpretation, organizational conflicts of interest, and small business compliance.Jim graduated with high honors from the George Washington University Law School, where he focused his studies on federal procurement law, was a member of the Law Review, and interned with the General Services Administration’s suspension and debarment office. Jim also holds a degree in theology magna cum laude from the Pontifical Gregorian University in Rome and a bachelor’s degree in classical languages and literature summa cum laude from the University of Kentucky, where he graduated Phi Beta Kappa.

tucker_james_blog_150x150.png

tucker_james_common_640x280.jpg

tucker_james_heroretina_2700x1160.jpg

tucker_james_mobileretina_750x1040.jpg

tucker_james_social_600x600.jpg

Of Counsel

Jim maintains an active practice in bid protests before the Government Accountability Office and contracting agencies and counsels clients in contract disputes and compliance obligations.

Jim Tucker is of counsel in Morrison Foerster’s Government Contracts and Public Procurement Practice Group and is based in the firm’s Washington, D.C. office. Jim’s practice runs the gamut of litigation and counseling in federal procurement matters, with an emphasis on bid protests, Cost Accounting Standards disputes, and small business matters.

James Tucker

<div style="margin-bottom: 15px;" class="videoWrapper"><iframe class="sticky-video" title="Meet Alex Ward, Government Contracts Practice Co-Chair" src="https://www.youtube-nocookie.com/embed/TkliwdSlTaQ?rel=0" frameborder="0" allow="autoplay; encrypted-media" allowfullscreen="1" title="iframe"></iframe></div>J. Alex Ward is co-chair of Morrison Foerster’s Government Contracts and Public Procurement group. His practice covers a full range of government contracts matters, including investigations, bid protests, claims, general litigation, corporate transactions, and counseling. Alex strives in all matters is to provide his clients the highest level of efficient and effective representation.Alex represents contractors in internal and external investigations, disclosures to the government, and qui tam litigation, with great success in reducing or eliminating his clients’ exposure through active engagement with the government. His work in this area includes obtaining numerous declinations and dismissals of False Claims Act cases in their earliest stages, sparing his clients the cost, risk, and exposure of litigation.He has also served as lead counsel in dozens of bid protests involving military and civilian agency procurements of a wide range of products and services, including all manner of pre- and post-award protests in the GAO, the U.S. Court of Federal Claims, and state tribunals, as well as appeals to the U.S. Court of Appeals for the Federal Circuit and size protest appeals before the SBA’s Office of Hearings and Appeals.Alex handles all aspects of the claims process, from the initial assessment and drafting of requests for equitable adjustment through litigation in the Boards of Contract Appeals and the Court of Federal Claims. Alex’s practice also covers the full gamut of other controversies confronting government contractors, including prime-sub, teaming partner, employer-employee, competitor, and indemnification disputes. His litigation work also includes a wide variety of pro bono engagements, in which he has represented both individual and institutional clients in matters ranging from immigration and criminal defense to sustainable procurement and protection of the environment.Prior to joining the firm, Alex served in the U.S. Army as a commissioned officer and an Assistant to the General Counsel of the Army responsible for civil works and international matters, and as a clerk for judges on the U.S. Courts of Appeals for the Armed Forces and the D.C. Circuit. He is a member of the Boards of the Morrison & Foerster Foundation and the Chesapeake Bay Foundation and of Law360’s Government Contracts Editorial Board.

ward_alex_blog_150x150.png

ward_alex_common_640x280.jpg

ward_alex_heroretina_2700x1160.jpg

ward_alex_mobileretina_750x1040.jpg

ward_alex_social_600x600.jpg

Alex is co-chair of Morrison Foerster’s Government Contracts and Public Procurement practice. His practice covers a full range of government contracts matters, including bid protests, claims, investigations, corporate transactions, and counseling.

J. Alex Ward

favicon.ico

favicon-16x16.png

favicon-32x32.png

apple-touch-icon.png

MoFo Favicons

Morrison Foerster’s Government Contracts Insights blog provides an in-depth analysis of news, developments, and trends impacting government contracting and procurement. Through Insights, attorneys from our nationally recognized Government Contracts and Public Procurement practice will offer a real-time assessment of the statutory, regulatory, legal, and business-related developments that are shaping the industry. This blog will also examine a full array of U.S. and non-U.S. public procurement issues, mindful that our clients compete in a global marketplace.Read about our <a href="http://govcon.mofo.com/editors/">Authors</a>.Never miss a post. Subscribe to get real-time updates.

Brad is a partner in Morrison Foerster’s Litigation Department, Managing Partner of the Austin office, and Chair of the firm’s Israel practice. He is the former Co-Chair of the firm’s Global Litigation Practice and the Government Contracts + Public Procurement Practice.

Bradley Wine

gov-con-feature-image-thumb1.jpg

Welcome to the Government Contracts Insights Blog

Welcome to the Government Contracts Insights Blog

gov-con-feature-image_(1)1.jpg

The United States Capitol building

Morrison Foerster’s Government Contracts Insights blog provides an in-depth analysis of news, developments, and trends impacting government contracting and proc

Announcements & Press

Blog - Terms of Use

Blog - Privacy Policy

Blog - Blog Disclaimer

Blog - Attorney Advertising

morrison-foerster-blog-logo.png

Provides insights and reports on the most current class actions lawsuits and product liability issues that affect consumer-facing companies.

Class Dismissed Blog

Class Dismissed

Looks behind the headlines to explore the trends, identify the opportunities, analyze the issues, and provide guidance for science and technology-based companies.

MoFo Tech

Mofo Tech

News and thought leadership from lawyers who are adding value to the legal profession and the communities we call home.

  External-Link

MoFo + Blog

Mofo+

Stay on top of emerging issues and stay informed of developments related to the law and business of social media.

Socially Aware

Our Government Contracts Insights blog provides in-depth analysis of developments and trends impacting U.S. government contracting and non-U.S. public procureme

Government Contracts Insights

  Linkedin

MoFo LinkedIN

Blog - Govcon RSS

Stay Connected

Never miss a post from Government Contracts Insights. Enter your email below to stay up-to-date.

Subscribe

The latest updates and analysis from Morrison Foerster

Morrison Foerster - Footer

The COVID-19 pandemic has introduced significant uncertainty for government contractors as agencies prepare for substantial disruptions, including the potential

Blogs -  Home Button

Home

Blog - Topics

Acquisition Regulations

Artificial Intelligence + Robotics

Compliance

Coronavirus

Cybersecurity & Data Privacy

Data Rights

Defense

Domestic Preferences

False Claims Act

Federal Procurement

Foreign Corrupt Practices Act

Grants

Health Care

Intellectual Property

International Public Procurement

Labor & Employment

Mergers & Acquisitions

National Security

Protests & Litigation

Resources

Schedule Contracting

Small Business

Topics

Blog - Editors

Editors

Blog - About

About

Blog - Subscribe

The Sovereign Acts Doctrine:   Understanding COVID-19 Implications For Your Government Contract

The Sovereign Acts Doctrine:   Understanding COVID-19 Implications For Your Government Contract | Government Contracts Insights

Kevin P. Mullen

Sandeep N. Nandivada

The COVID-19 pandemic has introduced significant uncertainty for government contractors as agencies prepare for substantial disruptions, including the potential closure of military installations.  See e.g., <a rel="noopener noreferrer" target="_blank" href="https://media2.mofo.com/v3/assets/blt5775cc69c999c255/blt9731ca39d8ba797c/627318dc0cffdf1eb1369e65/200318-ess-ct-section-chief-letter-contractors.pdf">Department of the Army COVID-19 Response Letter</a>; <a rel="noopener noreferrer" target="_blank" href="https://www.whs.mil/Portals/75/Coronavirus/Planning%20for%20Potential%20Novel%20Coronavirus%20Contract%20Impacts_DPC%20Signed%20and%20Dated%20Memorandum.pdf?ver=2020-03-11-114544-157">Department of Defense COVID-19 Planning Memo (Mar. 10, 2020)</a>.  Given the potential impacts the pandemic may have on ongoing contracting activities, we have identified a few best practices for contractors to bear in mind as the ongoing crisis persists.<ol><li>Get smart on the Sovereign Acts Doctrine. When the government acts as a contracting party, the law applicable to private entities governs the government’s contractual rights and duties.  Contractors doing business with the United States, therefore, can rely on the terms of a government contract to determine the legal remedy for government actions affecting performance.  The law also recognizes, however, that the actions of the United States, in its capacity as the sovereign, can affect a contractor’s performance of a government contract.  In such instances, the United States is absolved from liability for damages resulting from its sovereign acts, so long as those acts are “public and general” and not taken merely to avoid contractual obligations.  This common law defense to breach of contract is known as the Sovereign Acts Doctrine.  For a more detailed analysis of the ins and outs of the Doctrine, we encourage you to read our May 2019 article in Pratt’s Government Contracting Law Report.</li><li>Get smart on the excusable delay clause in your contract. Your contracts likely contain a FAR clause covering excusable delay.  For fixed-price contracts, that clause is <a rel="noopener noreferrer" target="_blank" href="https://www.law.cornell.edu/cfr/text/48/52.249-8">FAR 52.249-8, Default (Fixed Price Supply and Service)</a>, which provides that a contractor is not liable for excess costs for a failure to perform a contract arising from causes beyond its control and without its fault or negligence.  For cost-reimbursement contracts, the relevant clause is <a rel="noopener noreferrer" target="_blank" href="https://www.law.cornell.edu/cfr/text/48/52.249-14">FAR 52.249-14, Excusable Delays</a>, which similarly absolves contractors for such costs.  Contractors should promptly request schedule extensions to avoid any finding of a failure to perform.  If the government denies such requests for extensions, then contractors should be prepared to either submit a request for an equitable adjustment (REA) once damages are reasonably certain, or file a claim under the Contracts Disputes Act (CDA).</li><li>Get prepared for an REA or CDA claim. Given the rapid and continued progression of the COVID-19 pandemic, significant disruptions such as those contemplated by the Sovereign Acts Doctrine may soon become inevitable.  Contractors therefore should consider assembling their teams in anticipation of submitting an REA or claim once business operations return to normal.  Developing the underlying facts for an REA or claim is time-consuming, arduous work.  It therefore may be prudent to convene your potential REA/claim team in advance to allow the Company to collect relevant data in real-time for inclusion in the eventual REA or claim.</li></ol>If you have any questions regarding COVID-19 disruptions to your contracts, please reach out to one of the authors, or your standard MoFo contact.  Stay safe.Morrison & Foerster has mobilized a team of legal advisors across our firm’s global practices and disciplines to offer you timely legal and business advice as this global health crisis continues to quickly evolve.

More

The Tortured Regulations Department: SBA’s New Rule and Its Effect on Investments

Bid Protest Spotlight: Standing, Relationships, Responsibility

House’s Passage of the SAMOSA Act Signals Policy Shift Towards Government-Wide Enterprise Software Licensing

New DFARS Regulation on Small Business Affiliate Past Performance

Bid Protest Spotlight: Unclear Criteria, Data Rights, Conflicts

LinkedIN